優(yōu)美國華盛頓州工程總承包合同 （價款加雜費）（中英文對照）正式標準模板

美國華盛頓州工程總承包合同（價款加雜費）（中英文對照）美國華盛頓州工程總承包合同（價款加雜費）（中英文對照）IMPERIUMGRAYSHARBORLLCCONSTRUCTIONAGREEMENT（COSTPLUSFEE）中英文3萬余字，word文檔。學術交流請私信或評論留言TABLEOFCONTENTS總目錄1.TheWork第1條工程2.ContractDocuments.第2條.合同文件3.TotalPrice.第3條工程總價款4.Contractor’sFee.第4條承包商的雜費5.CostoftheWork.第5條工程價款6.CostsNottobeReimbursed.6.不予償付的費用。7.FinancingArrangements.7.融資安排8.Payment.8.款項支付9.ContractTimes.9.合同履行時間10.Changes.10.變更11.SiteInvestigation.11.工地現(xiàn)場調查12.ClaimsforDamages.12.索賠損害賠償13.Delay.13.工期延誤14.Contractor’sPaymentObligations.14.承包商的付款義務15.Liens.15.留置權16.Warranty.16.保修承諾17.DefectiveWork.17.瑕疵工程的處理18.Cleanup.18.清理場地19.SiteAccess.19.場地通行權20.PermitsandInspections.20.許可證和檢驗21.As-BuiltDrawings.21.竣工圖22.Owner’sConstructionandSeparateContracts.22.業(yè)主的施工和單獨的合同23.SafetyandEnvironment.23.安全和環(huán)境24.CompliancewithLaws.24.遵守法律25.IndependentContractor.25.獨立承包方26.Subcontracts.26.轉包合同27.Assignment.27.合同義務的轉讓28.Aesthetics28.業(yè)主對美學效應的決定29.Intentionallyomitted.29.本條款內容特意省略30.OwnershipofDrawingsandSpecifications.30.圖紙和規(guī)格的所有權31.Indemnity.31.賠償32.LimitationofLiability.32.責任限定33.TitleandRiskofLoss.33.所有權和損失風險34.Contractor’sInsuranceObligations.34.承包商的保險義務35.Owner’sInsuranceObligations.35.業(yè)主的保險義務36.Owner’sFailuretoPay.36.業(yè)主未能付款37.TerminationandCancellation.37.合同終止和撤銷38.ForceMajeure.38.不可抗力39.Exclusivity.39.專屬權40.DisputeResolution.40.爭議的解決41.GoverningLaw;Forum;AttorneyFees.41.管轄法律、法庭、律師費42.Modification;EntireAgreement.42.變更，協(xié)議的完整性43.Audit.43.審計44.Waiver.44.不構成權利放棄45.Severance.45.條款的可分割性46.JointDrafting.46.本協(xié)議由當事方共同草擬部分章節(jié)示例如下：9.ContractTimes.9.合同履行時間TimeisoftheessenceofthisAgreement,andspecificallyoftheprovisionsofthisSection9,whichsetsforththetimesofperformanceforvariouscomponentsofthisAgreement(the“ContractTimes”).時間是本協(xié)議的關鍵，特別是第9條的規(guī)定，其中規(guī)定了本協(xié)議各組成部分的履行時間（"合同時間"）。9.1TheContractorhasalreadycommencedperformanceoftheWorkpursuanttoaLimitedNoticetoProceedexecutedbytheOwnerandtheContractoronthedateof.9.1承包商已經根據(jù)業(yè)主和承包商在之日按照簽署的限定開工通知開始實施工程。9.2BoththeOwnerandContractorshallperformtheirobligationsunderthisAgreementincompliancewiththeProjectScheduleattachedasExhibitD,subjecttomodificationsofsuchProjectScheduleconsistentwithchangesintheContractTimespursuanttoSections10and13.9.2業(yè)主和承包商均應按照附件D中的項目日程表履行其在本協(xié)議下的義務，但可根據(jù)第10條和第13條對該項目日程表進行符合合同時間變更的修改。9.3TheContractorshallachieveMechanicalCompletion(ashereinafterdefined)oftheWorknotlaterthantheapplicabledatespecifiedonExhibitA,subjecttochangesintheseContractTimespursuanttoSections10and13(the“GuaranteedMechanicalCompletionDate”).MechanicalCompletionshallbeachievedwhen:9.3承包商應不遲于附件A規(guī)定的適用日期實現(xiàn)工程的機械完工（按照下文規(guī)定），但可根據(jù)第10和13條對這些合同時間進行變更（"保證機械竣工日期"）。機械竣工應在以下情況下實現(xiàn)：。(i)theWorkiscompletedinaccordancewiththisAgreement,exceptforpunchlistitems;(ii)theOwnerhasreceivedanyrequiredtemporaryorfinalcertificateofoccupancyfromthegovernmentalagencywithjurisdictionovertheProject;and(iii)theregisteredarchitectsorengineerswhodesignedportionsorcomponentsoftheWorkhaveissuedcertificatesofMechanicalCompletionastothoseportionsorcomponents.TheOwnershallnotoccupyorutilizetheWorkuntilitismechanicallycompletedexceptasagreedinwritinginadvancebytheContractor.(i)工程已按照本協(xié)議完成，但未完成的項目除外；(ii)業(yè)主已從對項目有管轄權的政府機構獲得任何所需的臨時或最終使用證書；以及(iii)設計工程部分或部件的注冊建筑師或工程師已對這些部分或部件出具機械完工證書。除非承包商事先書面同意，否則業(yè)主不得占用或使用該工程，直到其機械竣工。9.4TheContractorshallachieveFinalCompletion(ashereinafterdefined)oftheWorknotlaterthantheapplicabledatespecifiedonExhibitA,subjecttochangesintheseContractTimespursuanttoSections10and13(the?GuaranteedFinalCompletionDate?).FinalCompletionshallbeachievedwhen:(i)MechanicalCompletionoftheWorkhasbeenacknowledgedbytheOwnerandengineerinwriting;(ii)finallienwaiversandreleasesandotherdocumentsorinspectionsreasonablyrequiredbyOwner?sengineerorlenderhavebeendelivered;(iii)theContractorhasdeliveredthejobbooksandas-builtdrawings;(iv)alltheContractor?ssupplies,personnelandrubbishhavebeenremovedfromthesite;(v)allpunchlistitemshavebeencompleted(orotherwiseresolvedbyagreementoftheOwnerandtheContractor;and(vi)LiquidatedDamages,ifapplicable,havepaidtoOwner.9.4承包商應不遲于附件A規(guī)定的適用日期實現(xiàn)工程的最終竣工（按照下文所規(guī)定），但可根據(jù)第10條和第13條對合同時間進行變更（"保證最終竣工日期"）。最終竣工應在以下情況下實現(xiàn)(i)業(yè)主和工程師以書面形式認可工程的機械部分竣工；(ii)最后的留置權放棄和結清以及業(yè)主的工程師或貸款人合理要求的其他文件或檢查已經交付；(iii)承包商已經交付工程簿和竣工圖。(iv)承包商的所有用品、人員和垃圾已從工地上移走；(v)所有清單上的項目都已完成（或經業(yè)主和承包商同意解決）；(vi)違約金，如果適用，已支付給業(yè)主。9.5Inlieuofactualdelaydamages,theOwnerandContractoragreethatifMechanicalCompletionisnotachievedbytheapplicableGuaranteedMechanicalCompletionDate,theamountoftheOwner?sactualdamageswillbedifficulttodetermine.Accordingly,theOwnerandtheContractoragreethatintheeventtheContractorfailstoachieveMechanicalCompletionbytheapplicableGuaranteedMechanicalCompletionDate,theContractorshallpaytotheOwnerasliquidateddamagestocompensatetheOwnerfordamagesrelatedtothedelayedcompletionoftheWork(?LiquidatedDamages?)seventy-fivethousanddollarsperweek($75,000/week)foreverycalendarweekContractorfailstomeettheGuaranteedMechanicalCompletionDatereferencedinparagraph9.3(lessthenfullweeksshallbepro-rated;provided,however,thattheaggregateamountofliquidateddamagescannotexceedsixhundredthousanddollars($600,000).9.5為了代替實際的延遲損害賠償，業(yè)主和承包商同意，如果在適用的保證機械部分竣工日期之前沒有實現(xiàn)機械竣工，業(yè)主的實際損害賠償金額將很難確定。因此，業(yè)主和承包商同意，如果承包商未能在適用的保證機械竣工日期前實現(xiàn)機械竣工，承包商應向業(yè)主支付違約金，以補償業(yè)主與延遲完成工程有關的損失（即"違約金"），每周7.5萬美元（75,000美元/周），用于承包商未能達到第9條中涉及的保證機械竣工日期的每個日歷周（不足整周應按比例計算）；但是，違約金總額不能超過六十萬美元（600,000美元）。9.6TheOwnerandContractoragreethatifMechanicalCompletionfortheWorkoccurspriortotheGuaranteedMechanicalCompletionDate,theOwnershallpaytotheContractorasabonusseventy-fivethousanddollarsperweek($75,000/week)foreverycalendarweektheWorkreachesMechanicalCompletionpriortoitsGuaranteedMechanicalCompletionDate(lessthenfullweeksshallbepro-rated);providedthattheaggregateamountofthebonusshallnotexceedthreehundredthousanddollars($300,000).9.6業(yè)主和承包商同意，如果工程的機械完工時間早于保證機械完工日期，業(yè)主應向承包商支付每周七萬五千美元（75,000美元/周）的獎金，用于在保證機械竣工日期之前達到機械竣工的每一個日歷周（不足一周應按比例計算）；但獎金總額不得超過三十萬美元（$300,000）。10.Changes.10.變更WithoutinvalidatingthisAgreement,theOwnerorContractormayorderchangesintheWorkwithinthegeneralscopeofthisAgreementconsistingofadditions,deletionsorotherrevisions(eacha?ChangeOrder?).ItisexpresslyunderstoodandagreedthattheContractorshallnotbeentitledtoadditionalcompensationoranextensionoftheContractTimesforanyextraoradditionalworkorforworkoutsidethescopeoftheAgreement,exceptassetoutinthisSection10.在無損本協(xié)議效力的情況下，業(yè)主或承包商可以在本協(xié)議的一般范圍內指令對工程進行變更，包括增加、刪除或其他修訂（以"更改單"分別處理）。各方同意，承包方無權就任何額外的或附加的工程或協(xié)議范圍以外的工程獲得額外的補償或延長合同時間，但本第10條規(guī)定的情況除外。10.1TheOwnerandContractorshallenterintoawrittenChangeOrdersignedbybothpartiesstatingthechangedWorktobeperformed,anyagreedchangesintheContractor’sFee,andanyagreedchangesintheContractTimes.AnyextraorchangedworkperformedwithoutpriorwrittendirectionorapprovalofOwnershallnotbecompensatedbyOwner.10.1業(yè)主和承包商應簽訂一份由雙方簽署的書面變更單，說明要實施的變更工程、承包商費用的任何商定變更以及合同時間的任何商定變更。任何未經業(yè)主事先書面指示或批準而進行的額外或變更的工程，業(yè)主不得給予補償。10.2IftheOwnerandContractorareunabletoagreeonthechangesintheContractor’sFeeorthechangesintheContractTimes,theOwnermaydirecttheContractorinwritingtoperformthechangedWorkandtheContractorshallimmediatelyperformsuchWork.Insuchcase,andsubjecttoSection4above,(i)theContractor?sFeeshallbecalculatedinaccordancewiththefollowingmark-upschedule,asappliedtotheactualchangeintheCostsoftheWork:10.2如果業(yè)主和承包商無法就承包商費用的變更或合同時間的變更達成一致，業(yè)主可以書面指示承包商實施變更的工程，承包商應立即實施這些工程。在這種情況下，在遵守上述第4條的前提下，（i）承包方的費用應按照以下加價表計算，并適用于工程費用的實際變更。20%onstafflaborandsupervision;15%ondirectandfabricationlabor;10%onmaterialsandequipmentand5%onSubcontractors;and(ii)theContractTimesshallbeadjustedbasedonthereasonableactualimpactontheContractor?sperformanceoftheWork.IfthepartiesareunabletoagreeonthechangesintheContractor?sFeeorintheContractTimes,theOwnershalldetermineanysuchchanges,whichshallbesubjecttoarbitrationifdemandedbytheContractor.20%的人員勞動和監(jiān)督；15%的直接勞動和制造勞動；10%的材料和設備以及5%的分包商；以及（ii）合同時間應根據(jù)對承包商履行工程的合理實際影響進行調整。如果雙方無法就承包方費用或合同時間的變化達成一致，業(yè)主應確定任何此類變化，如果承包方提出要求，應進行仲裁。11.SiteInvestigation.11.工地現(xiàn)場調查TheContractorwarrantsthat,byexamination,ithassatisfieditselfastothegeneralnatureandlocationoftheWork,thegeneralcharacter,quantityandkindofmaterialstobeencountered,theequipmentrequiredandthegeneralconditionsandothermatterswhichmayinanymanneraffecttheWork.TheOwnershallfurnishallsitesurveysandlegaldescriptionsrequiredfortheWork,ifany,andContractorshallbeentitledtorelyuponthesame.Contractorexpresslydisclaimsallliabilityforlatentorsubsurfaceconditions.Notwithstandingtheforegoing,ContractorshallberesponsibleforlocatingandmanagingtheWorkaroundanyexistingundergroundpipesandelectricallines.承包商保證，通過審查，它已對工程的一般性質和位置，將遇到的材料的一般性質、數(shù)量和種類，所需設備以及一般條件和其他可能以任何方式影響工程的事項感到滿意。業(yè)主應提供工程所需的所有現(xiàn)場調查和法律所規(guī)定的描述（如有），承包商應有權依賴這些。承包商明確表示對潛在的或地下的條件不承擔任何責任。盡管有上述規(guī)定，承包方應負責定位和管理任何現(xiàn)有地下管道和電線周圍的工程。12.ClaimsforDamages.12.索賠損害賠償IftheContractorhasanyclaimforadditionalcompensationorotherdamagesagainsttheOwner,theContractorshallgivetheOwnerwrittennoticeofsuchclaimwithinten(10)daysaftertheContractorobtainsknowledgeoftheeventallegedtohavegivenrisetotheclaim.IftheContractorfailstogivesuchnotice,theclaimshallbedeemedwaivedandforeverdischarged.如果承包方對業(yè)主有任何額外的賠償或其他損失的要求，承包方應在知悉據(jù)稱引起索賠的事件后十（10）天內向業(yè)主發(fā)出書面索賠通知。如果承包商未能發(fā)出這樣的通知，則應視為放棄并不再提出索賠。13.Delay.13.工期延誤IftheContractorisready,ableandwillingtoworkbutisdelayedatanytimeduringtheprogressoftheWorkbyanyactorneglectoftheOwner,changesorderedintheWorkoraneventofForceMajeure(asdefinedinSection38),theContractTimesshallbeextendedbythenumberofcalendardaysthattheWorkasawholeisdelayedpursuanttothisSection13.如果承包商準備就緒，能夠并愿意實施工程，但由于業(yè)主的任何行為或疏忽，在工程進展中的任何時候被延誤，在工程中指令的變更或不可抗力的事件（如第38條所規(guī)定），合同工期應根據(jù)本第13條的規(guī)定對整個工程被延遲的日歷天數(shù)做延展。TheContractorshallsubmitanyclaimforanextensionoftimetotheOwner,inwriting,withinten(10)daysafterthecommencementofthedelay.Onlyoneclaimisnecessaryintheeventofacontinuingdelay.Thewrittenclaimforextensionoftimeshallstatethenumberofdaysclaimedandthereasonforthedelay.Anyclaimforatimeextensionwhichisnotpresentedinaccordancewithallrequirementsofthisparagraphshallbedeemedwaivedandforeverdischarged.承包商應在延誤開始后十（10）天內書面向業(yè)主提出任何延展工期的要求。在持續(xù)延誤的情況下，只需要提出一次索賠。延展工期的書面要求應說明要求的天數(shù)和延誤的原因。任何未按照本段所有要求提出的延期要求，應被視為放棄并不再提出。13.1IfadverseweatherconditionsorothereventsofForceMajeurearethebasisforaclaimforanextensionoftheContractTimes,suchclaimshallbeallowedonlytotheextentitisdocumentedbydatasubstantiatingthattheweatherconditions(i)wereunusuallyseverefortheAberdeenareaduringtheperiodoftimeinquestion,(ii)unusuallyseveretobedefinedasoccurrencesofinexcessof1.50inchesofprecipitationfor2ormoreconsecutivedays,and/orprecipitationinexcessof2.00inchesofprecipitationfor1ormoreconsecutivedays,and/orprecipitationinexcessof1.00inchesfor3ormoreconsecutivedays,asmeasuredatHoquiam’sBowermanAirport,(iii)couldnothavebeenreasonablyanticipatedand(iiii)hadanadverseeffectonthescheduledperformanceoftheWork.13.1如果惡劣的天氣條件或其他不可抗力事件是要求延長合同工期的依據(jù)，這種要求應僅在有數(shù)據(jù)證明天氣條件(i)在有關時間段內對阿伯丁地區(qū)異常嚴重的情況下被允許，(ii)異常嚴重是指發(fā)生超過1.50英寸的降水連續(xù)2天或更多，和/或超過2.00英寸的降水連續(xù)1天或更多，和/或超過1.00英寸的降水連續(xù)3天或更多，如在霍奎姆的鮑爾曼機場測量，（iii）不能合理預期和（iiii）對工程的預定實施有不利影響。13.2AnextensionoftheContractTimesshallbeallowedonlytotheextentthatsuchdelaywasnotcausedbyanyfaultornegligenceoftheContractor,Subcontractors,anyonedirectlyorindirectlyemployedbyanyofthemorforwhoseactsanyofthemmaybeliable.13.2只有在這種延誤不是由承包商、分包商、他們中任何一方直接或間接雇用的任何人或他們中任何一方可能對其行為負責的任何過失或疏忽造成的情況下，才應允許延長合同工期。13.3IftheWorkisstoppedorsuspendedbyorderofanycourtorgovernmentalauthority,withinseven(7)daysafterreceiptofnoticethatsuchWorkstoppageorsuspensionisremoved,theContractorshallcompletetheWorkasexpeditiouslyasreasonablypossible.Intheeventofsuchstoppageorsuspension,theContractorshallbeentitledtoanextensionintheContractTimesequaltothelengthofthedelay(thelengthofthestoppageorsuspensionplustheseven(7)orfewerdaysafternoticewithinwhichtheContractorrecommencestheWork)plusanequitableincreaseintheContractor’sFee.13.3如果工程因任何法院或政府當局的命令而停止或暫停，在收到取消這種工程停頓或暫停的通知后七（7）天內，承包方應在合理范圍內盡快完成工程。在這種停工或暫停的情況下，承包方應有權延長合同工期，相當于延誤的期間（停工或暫停的期間加上通知后的七（7）天或更少的時間，承包方重新開始工程），加上承包方費用的合理增加。14.Contractor’sPaymentObligations.14.承包商的付款義務TheContractorshallpayallofitsobligationsarisingoutoforinconnectionwiththeWorkinatimelymanner.UponreasonableevidencethatoneormoreSubcontractorshavenotbeenorwillnotbepaid,theOwnermaypayanyoftheContractor?spaymentobligationsdirectlytotheclaimantorbymultiplepayeechecktotheContractorandtheclaimantandpartiesininterveningtiers,ifany,anddeducttheamountofsuchpaymentfromamountsdueortobecomeduetotheContractor.UpontheOwner?swrittenrequest,theContractorshallfurnishtotheOwnerallinformationrequiredtofacilitatesuchdirectormultiplepayeepayments,includingwithoutlimitationacompletelistingofoutstandingamountsowedtoallSubcontractors.承包商應及時支付由工程引起的或與工程有關的所有債務。如果有合理的證據(jù)表明一個或多個分包商沒有或不會得到付款，業(yè)主可以將承包商的任何付款債務直接支付給索賠人，或通過多個收款人的支票支付給承包商和索賠人以及中間層的各方（如有），并從應付給或將應付給承包商的款項中扣除這種付款的數(shù)額。根據(jù)業(yè)主的書面要求，承包商應向業(yè)主提供所有必要的信息，以促進這種直接或多個收款人的付款，包括但不限于欠所有分包商的未付款項的完整清單。15.Liens.15.留置權TheContractorshallkeeptheProjectandProjectpropertyfreeandclearofallconstructionliensarisingoutoftheWork.IfanyliensarisingoutoftheWorkarefiledbyanypersonorentity,includingwithoutlimitationanySubcontractor,theContractorshall,atitscostandwithinten(10)daysafterdemandfromtheOwner,satisfysaidlienorpostandperfectabondunderapplicablelawsoastoremovethelienfromtheProjectandProjectproperty.Theabovenotwithstanding,nothinghereinshallprecludeordepriveContractoroftherighttofileandmaintainalienontheProjectorProjectpropertyintheeventofnon-paymentbyOwner.承包商應保持項目和項目財產不存在因工程而產生的所有建筑留置權。如果任何個人或實體，包括但不限于任何分包商，提出任何工程留置權，承包商應在業(yè)主要求后的十（10）天內，以其價款清償上述留置權或交易賬目張貼和完善債券，以消除項目和項目財產的留置權。盡管有上述規(guī)定，但在業(yè)主未付款的情況下，本條款不應排除或剝奪承包商對項目或項目財產提出和維持留置權的權利。16.Warranty.16.保修承諾16.1TheContractorwarrantstotheOwnerthatthematerialsandequipmentfurnishedunderthisAgreementwillbe(a)newandofgoodquality;(b)freefromdefectsinmaterialsandworkmanship,unlessotherwiseapprovedinwritinginadvancebytheOwner,and(c)thattheWorkwillbeperformedinagoodandworkmanlikemannerandinaccordancewiththePlansandallapplicablecodes,lawsandstandards.16.1承包商向業(yè)主保證，根據(jù)本協(xié)議提供的材料和設備將是(a)新的和高質量的；(b)沒有材料和工藝上的缺陷，除非事先得到業(yè)主的書面批準，以及(c)工程將以良好和精湛的?方式進行，并符合計劃和所有適用規(guī)范、法律和標準。TheContractorshallcollectandsubmittotheOwner,uponMechanicalCompletionoftheWork,allwarrantiesfromSubcontractorssupplyingmaterials,equipmentorcomponentsincorporatedintotheProject,andtheContractorherebyassignstotheOwneralloftheContractor’srightsundersuchwarranties.TheContractoragreesthatsuchwarrantiesfromthoseSubcontractorsreferencedinExhibitFshallcomplywiththerequirementssetoutinExhibitF.承包商應在工程機械完工收集并向業(yè)主提交材料、設備或部件的分包商對項目的所有保證，并且承包商在此將承包商在這些保證下的所有權利轉讓給業(yè)主。承包商同意，附件F中提到的那些分包商的這種保證應符合附件F中的要求。16.2TheContractorwillrecommendtoOwnerallprocessandconstructionimprovementsthatitbelievesingoodfaithwouldoptimizetheProjectconstructionandoperations,providedthatContractor’sliabilityforbreachesofsuchwarrantyshallbelimitedtoinstancesofgrossnegligenceorwillfulmisconduct.16.2承包商將向業(yè)主推薦其真誠地認為可以優(yōu)化項目建設和運營的所有工藝和施工改進措施，但承包商對違反這種保證的責任應限于嚴重疏忽或故意不當行為的情況。16.3Thefollowingshallgovernthedurationsofthewarrantiesdescribedabove.ThebasewarrantyperiodwillcommencewhenMechanicalCompletionhasbeenachievedandwillcontinueforthelesserof(i)twelve(12)monthsfromtheapplicableGuaranteedMechanicalCompletionDate;or18monthsaftertheapplicableFinalCompletionDate(“BaseWarrantyPeriod”).WarrantyforanyrepairsorreplacementsshallcommenceonthedatetherepairorreplacementiscompletedandcontinueuntilthelateroftheexpirationoftheBaseWarrantyPeriodorsix(6)monthsfromthedateofcompletionoftherepairorreplacementandshallnotexceedamaximumofthirty(30)monthsfromtheMechanicalCompletionDate(the“RepairWarrantyPeriod”)(theBaseWarrantyPeriodplustheRepairWarrantyPeriodarecollectivelyreferredtoasthe“WarrantyPeriod”).Contractorshall,asmitigationofthedamagessufferedbytheOwner,atContractor’sowncostandexpense(includingthecostoflaborandequipment)promptlyrepairorreplacewithmaterialsofnewandgoodqualityanyWorkormaterialswhichfailtocomplywiththewarrantyduringtheWarrantyPeriod.16.3上述保證的期限應遵循以下規(guī)定?；颈ＷC期將從實現(xiàn)機械竣工時開始，并將持續(xù)到(i)從適用的保證機械完成日期開始的十二(12)個月；或適用的最終完成日期之后的18個月（"基本保證期"），以較低者為準。任何修理或更換的保證應從修理或更換完成之日開始，并持續(xù)到基本保證期屆滿或從修理或更換完成之日開始的六（6）個月（以較晚者為準），并且不應超過從機械完成日期開始的最多三十（30）個月（"修理保證期"）（基本保證期加上修理保證期統(tǒng)稱為"保證期"）。承包商應在保修期內及時修理或用新的、質量好的材料更換任何不符合保修要求的工程或材料，以減輕業(yè)主的損失，費用由承包商自行承擔（包括勞動力和設備的費用）。17.DefectiveWork.17.瑕疵工程的處理TheWorkshallbesubjecttoobservationandapprovalbytheOwnerandrepresentativesofgovernmentalagencieswithjurisdictionovertheProject.Withoutlimitingtheeffectofthepriorsentence,allportionsorcomponentsoftheWorkdesignedbyregisteredarchitectsorengineersshallalsobesubjecttotheirobservationandapproval.TheContractorshallpromptlycorrect,atnocosttotheOwner,allWorkreasonablyrejectedbytheOwnerandallWorkrejectedbysuchagencyrepresentatives.ShouldtheContractorfailtocorrectrejectedWork,theOwnermaycorrectsuchWorkandtheContractorshallpaytheOwner’sactualcostsofcorrection.本工程應接受業(yè)主和對本工程有管轄權的政府機構代表的檢測和批準。在不限制前述規(guī)定效力的情況下，由注冊建筑師或工程師設計的工程的所有部分或組件也應接受他們的檢測和批準。承包商應及時糾正被業(yè)主合理拒絕的所有工程和被這些機構代表拒絕的所有工程，而不需要業(yè)主承擔任何費用。如果承包商未能糾正被拒絕的工程，業(yè)主可以糾正這些工程，承包商應支付業(yè)主的實際糾正費用。18.Cleanup.18.清理場地TheContractoratalltimesshallkeeptheProjectpremisesreasonablyfreefromwaste,debrisandotherexcessmaterialscausedbytheWork,andshallleavethepremisesin“broomclean”conditionattheendofeachdayofWork.UponbothsubstantialandfinalcompletionoftheWork,theContractorshallremoveallwaste,debris,tools,equipmentandexcessmaterialsfromtheProjectsite,shallproperlydisposeofallsuchitems,andshallleavethesiteinaneatandorderlycondition.ShouldtheContractorfailtoperformitsobligationsunderthisSection,theOwnermaydosoattheContractor’sexpense.承包商在任何時候都應保持項目場地合理地無廢物、碎片和其他由工程引起的多余材料，并應在每天工程結束時使場地處于"掃帚清潔"狀態(tài)。在工程基本完成和最終完成時，承包方應從項目現(xiàn)場清除所有廢物、碎片、工具、設備和多余的材料，應妥善處理所有這些物品，并應使現(xiàn)場處于整潔有序的狀態(tài)。如果承包方未能履行本節(jié)規(guī)定的義務，業(yè)主可以這樣做，費用由承包方承擔。19.SiteAccess.19.場地通行權TheContractorshallallowtheOwneranditsrepresentativesaccessatallreasonabletimestotheProjectsiteandtotheWorkwhereverbeingperformed.InvisitingtheProjectsiteandtheWork,theOwneranditsrepresentativesshallnotunreasonablyinterferewithordelaytheperformanceoftheWork,whetherperformedbytheContractororSubcontractors.承包商應允許業(yè)主及其代表在所有合理的時間進入項目現(xiàn)場和正在實施的工程。在查看項目現(xiàn)場和工程時，業(yè)主及其代表不應不合理地干擾或拖延工程的進行，無論是由承包商還是分包商進行。20.PermitsandInspections.20.許可證和檢驗IfrequestedbyOwner,theContractorshallsecureandinitiallypayforthebuildingpermit,plancheckfees,andallotherpermitsandfees,testsandinspectionsbygovernmentalagenciesrequiredandnecessaryfortheperformanceandcompletionoftheWorkbytheContractorandSubcontractors.TheOwnershallreimbursetheContractorforthecostofthebuildingpermit(butthereshallbenoContractorfeeormarkupthereon).TheContractor’sothercostsincurredunderthisSection20shallbereimbursedbytheOwneraspartoftheCostoftheWork,excepttotheextenttestsorinspectionshereunderdisclosedefectiveornonconformingWorkcausedbythefaultornegligencereferencedinSection6.6.如果業(yè)主要求，承包商應確保并先行支付建筑許可證、計劃檢查費，以及承包商和分包商執(zhí)行和完成工程所需的政府機構的所有其他許可證和費用、檢測和檢查。業(yè)主應向承包商償付建筑許可證的費用（但不應該有承包商的費用或加價）。承包商根據(jù)第20條所產生的其他費用應作為構成價款的一部分由業(yè)主償還，除非根據(jù)本條規(guī)定的檢測或檢查發(fā)現(xiàn)有缺陷或不符合要求的工程是屬于第6.6條中規(guī)定的過失或疏忽造成的。20.1TheOwnershallcontractandpayforalltestsandinspectionsoftheWorkbythirdpartiesrequiredandnecessaryfortheperformanceandcompletionoftheWorkbytheContractorandSubcontractors;providedthattheContractorratherthantheOwnershallpayforsuchtestsandinspectionstotheextenttheydisclosedefectiveornonconformingWork.TheContractor’scostsincurredunderthisSection20.1shallbereimbursedaspartoftheCostoftheWork,excepttotheextentthedefectiveornonconformingWorkiscausedbythefaultofnegligencereferencedinSection6.6.TheContractorshallgivetheOwnerreasonablenoticeofthetimeforthetestsandinspectionsreferencedinthisSection業(yè)主應與第三方簽約并支付承包商和分包商實施和完成工程所需的所有檢測和檢查費用；但如果這些檢測和檢查發(fā)現(xiàn)有缺陷或不符合要求的工程，則費用由承包商而不是業(yè)主支付。承包商根據(jù)本第20.1條發(fā)生的費用應作為工程費用的一部分予以補償，但由于第6.6條規(guī)定的過失造成的缺陷或不合格的工程除外。承包商應向業(yè)主發(fā)出合理的通知，說明本第20.1條中規(guī)定的檢測和檢查的時間。20.2ObservationsorapprovalsbytheOwner,architectorothers(includingthirdparties)shallnotrelieveContractorofitssoleresponsibilityforconstructionmeans,methods,techniques,sequences,safetyissues,andprocedures,andforsupervising,coordinatingandperformingalloftheWork.20.2業(yè)主、建筑師或其他人（包括第三方）的觀察或批準不應解除承包商對施工手段、方法、技術、順序、安全問題和程序以及對監(jiān)督、協(xié)調和實施所有工程的全部責任。21.As-BuiltDrawings.21.竣工圖TheContractorshallmaintainduringtheprogressoftheWorkas-builtdrawingsindicatingthecurrentstatusoftheWorkasactuallyperformed.UponMechanicalCompletionoftheWork,theContractorshallprepareafinalversionofsuchas-builtdra